AN OFFERING STATEMENT PURSUANT TO REGULATION A RELATING TO THESE SECURITIES HAS BEEN FILED WITH THE SECURITIES AND EXCHANGE COMMISSION. INFORMATION CONTAINED IN THIS PRELIMINARY OFFERING CIRCULAR IS SUBJECT TO COMPLETION OR AMENDMENT. THESE SECURITIES MAY NOT BE SOLD NOR MAY OFFERS TO BUY BE ACCEPTED BEFORE THE OFFERING STATEMENT FILED WITH THE COMMISSION IS QUALIFIED. THIS PRELIMINARY OFFERING CIRCULAR SHALL NOT CONSTITUTE AN OFFER TO SELL OR THE SOLICITATION OF AN OFFER TO BUY NOR MAY THERE BE ANY SALES OF THESE SECURITIES IN ANY STATE IN WHICH SUCH OFFER, SOLICITATION OR SALE WOULD BE UNLAWFUL BEFORE REGISTRATION OR QUALIFICATION UNDER THE LAWS OF ANY SUCH STATE. WE MAY ELECT TO SATISFY OUR OBLIGATION TO DELIVER A FINAL OFFERING CIRCULAR BY SENDING YOU A NOTICE WITHIN TWO BUSINESS DAYS AFTER THE COMPLETION OF OUR SALE TO YOU THAT CONTAINS THE URL WHERE THE FINAL OFFERING CIRCULAR OR THE OFFERING STATEMENT IN WHICH SUCH FINAL OFFERING CIRCULAR WAS FILED MAY BE OBTAINED.

FORM 1-A

Regulation A Offering Statement

Part II – Offering Circular

Energea Portfolio 1 LLC

9 Cedar Lane

Old Saybrook, CT 06475

(860) 316-7466

www.energea.com

June 5, 2020

This Offering Circular Follows the Form 1-A Disclosure Format

Energea Portfolio 1 LLC is a limited liability company organized under the laws of Delaware, which we refer to as the “Company.” The Company is offering to sell to the public up to $50,000,000 per limited liability company interests designated as “Class A Investor Shares.” The initial price of the Class A Investor Shares will be $1.00 per share and the minimum initial investment is $500.

We are selling these securities directly to the public through the website, www.energea.com. Currently, we are not using a placement agent or a broker and we are not paying commissions to anyone.

We might change the price of the Class A Investor Shares in the future. See “Securities Being Offered – Price of Class A Investor Shares” on page 28.

We refer to the offering of Class A Investor Shares pursuant to this Offering Circular as the “Offering.” The Offering will begin as soon as our Offering Statement is “qualified” by the U.S. Securities and Exchange Commission (“SEC”) and will end on the sooner of (i) a date determined by the Company, or (ii) the date the Offering is required to terminate by law.

The purchase of these securities involves a high degree of risk. Before investing, you should read this whole Offering Circular, including “Risks of Investing” starting on page 9.

THE UNITED STATES SECURITIES AND EXCHANGE COMMISSION DOES NOT PASS JUDGEMENT UPON THE MERITS OF OR GIVE ITS APPROVAL TO ANY SECURITIES OFFERED OR THE TERM OF THE OFFERING. NOR DOES IT PASS JUDGEMENT UPON THE ACCURACY OR COMPLETENESS OF ANY OFFERING CIRCULAR OR OTHER SELLING LITERATURE. THESE SECURITIES ARE OFFERED PURSUANT TO AN EXEMPTION FROM REGISTRATION WITH THE COMMISSION; HOWEVER, THE COMMISSION HAS NOT MADE AN INDEPENDENT DETERMINATION THAT THE SECURITIES OFFERED HEREUNDER ARE EXEMPT FROM REGISTRATION.

GENERALLY, IF YOU ARE A NON-ACCREDITED INVESTOR NO SALE MAY BE MADE TO YOU IN THIS OFFERING IF THE AGGREGATE PURCHASE PRICE YOU PAY IS MORE THAN 10% OF THE GREATER OF YOUR ANNUAL INCOME OR NET WORTH. DIFFERENT RULES APPLY TO ACCREDITED INVESTORS AND NON-NATURAL PERSONS. BEFORE MAKING ANY REPRESENTATION THAT YOUR INVESTMENT DOES NOT EXCEED APPLICABLE THRESHOLDS, WE ENCOURAGE YOU TO REVIEW RULE 251(d)(2)(i)(C) OF REGULATION A. FOR GENERAL INFORMATION ON INVESTING, WE ENCOURAGE YOU TO REFER TO WWW.INVESTOR.GOV. FOR MORE INFORMATION, SEE THE “Limits on How Much Non-Accredited Investors Can Invest” SECTION STARTING ON PAGE 34.

NEITHER THE SECURITIES AND EXCHANGE COMMISSION NOR ANY STATE SECURITIES COMMISSION HAS APPROVED OR DISAPPROVED OF THESE SECURITIES OR PASSED UPON THE ADEQUACY OR ACCURACY OF THIS OFFERING CIRCULAR. ANY REPRESENTATION TO THE CONTRARY IS A CRIMINAL OFFENSE.

NORTH AMERICAN SECURITIES ADMINISTRATORS ASSOCIATION UNIFORM LEGEND:

YOU SHOULD MAKE YOUR OWN DECISION AS TO WHETHER THIS OFFERING MEETS YOUR INVESTMENT OBJECTIVES AND RISK TOLERANCE LEVEL. NO FEDERAL OR STATE SECURITIES COMMISSION HAS APPROVED, DISAPPROVED, ENDORSED, OR RECOMMENDED THIS OFFERING. NO INDEPENDENT PERSON HAS CONFIRMED THE ACCURACY OR TRUTHFULNESS OF THIS DISCLOSURE, NOR WHETHER IT IS COMPLETE. ANY REPRESENTATION TO THE CONTRARY IS ILLEGAL.

THESE SECURITIES ARE SUBJECT TO RESTRICTIONS ON TRANSFERABILITY BY CONTRACT AND THERE WILL BE NO READY MARKET FOR RESALE. YOU SHOULD COULD BE REQUIRED TO BEAR THE FINANCIAL RISKS OF THIS INVESTMENT FOR AN INDEFINITE PERIOD OF TIME.

EXECUTIVE SUMMARY

Our Story

The world wants and needs solar energy. Once the stuff of warnings from scientists about what might happen, the global effects of climate change are happening. Once-in-a-century floods, melting glaciers, fires burning in Australia, the rapid extinction of species, ocean water threatening Miami and Manhattan – all due in large part to the carbon emissions of human beings.

While too many political leaders bury their heads in the sand, the good news is that American entrepreneurs are rising to the occasion.

Mike Silvestrini co-founded Greenskies Renewable Energy, LLC (“Greenskies”) with $35,000 in 2008. Under Mike’s management, Greenskies built more than 400 solar projects across the United States, counting among its electricity customers Wal-Mart, Sam’s Club, Amazon, Target, municipalities, schools, universities, and large electric utilities. Greenskies was sold in 2017 for an enterprise value in excess of $165 million.

The 400+ solar energy projects developed by Greenskies keep approximately 250,000 metric tons of carbon dioxide out of the Earth’s atmosphere every year.

Mike and fellow energy entrepreneur Chris Sattler are now applying the lessons from Greenskies around the world, developing solar energy projects from Africa to South America.

Among the most compelling markets is Brazil, where rising energy prices, a decrease in the price of developing solar projects, a large and diverse market of electricity buyers, and favorable national polices have contributed to a rapidly growing industry.

Mike and Chris formed the Company to buy or build solar energy projects in Brazil (each, a “Project”). Our Projects will share the following characteristics:

The Offering

The Company is offering to investors up to $50,000,000 of Class A Investor Shares to finance the purchase and development of Projects.

From the cash flow generated by a Project, if any, owners of the Class A Investor Shares will have the right to receive:

Owners of the Class A Investor Shares will have no voting rights.

CAUTION: ALTHOUGH THE CASH FLOW FROM OUR PROJECTS WILL LARGELY BE ESTABLISHED BY CONTRACT IN ADVANCE, THERE IS NO GUARANTY THAT OUR PROJECTS WILL GENERATE ANY POSITIVE CASH FLOW.

Apart from the potential economic returns, an Investor who purchases $10,000 of Class A Investor Shares will keep approximately 11 metric tons of carbon dioxide out of the atmosphere each year.

Table of Contents

RISKS OF INVESTING

BUYING CLASS A INVESTOR SHARES IS SPECULATIVE AND INVOLVES SIGNIFICANT RISK, INCLUDING THE RISK THAT YOU COULD LOSE SOME OR ALL OF YOUR MONEY. THIS SECTION DESCRIBES SOME OF THE MOST SIGNIFICANT FACTORS THAT WE BELIEVE MAKE AN INVESTMENT IN THE NOTES RISKY. THE ORDER IN WHICH THESE FACTORS ARE DISCUSSED IS NOT INTENDED TO SUGGEST THAT SOME FACTORS ARE MORE IMPORTANT THAN OTHERS.

The Track Record of Our Principals Does Not Guaranty Success: The principals of the Company have been involved in the solar industry for approximately 13 years, developing more than 400 solar projects. See “Past Performance – Our Track Record” on page 25. However, past performance is never a guaranty of future results, and the success of our principals in other solar projects does not guaranty that the Company will be successful.

Risks Associated with Renewable Energy Projects: The market for renewable energy is changing rapidly, and its future is uncertain. If renewable technology proves unsuitable for widespread commercial deployment or if demand for renewable energy products, especially solar energy products, fails to develop sufficiently, our Projects might not be able to generate enough revenues to achieve and sustain profitability. The factors influencing the widespread adoption of renewable energy technology include but are not limited to: cost-effectiveness of renewable energy technologies as compared with conventional technologies; performance and reliability of renewable energy products as compared with conventional energy products; success of other alternative technologies such as fuel cells; fluctuations in the prices of oil and other fossil fuels; and government policies. We have no control over any of those factors.

Fluctuations in Income: Our rental agreements with customers typically provide for fluctuations in rent based on changes in energy prices and/or changes in consumer prices. Thus, it is possible that our income from one or more Projects could decrease.

Competition: There are many solar developers actively building projects in Brazil. Some are multi-national independent power producers (e.g., ENEL, Engie), which tend to focus on utility-scale solar auctions and are less focused on smaller projects. In addition to these large established players, there are several smaller developers we view as our direct competition. Aggressive pricing by competitors or the entrance of new competitors could reduce our chances of success.

Our Customers Might Default: The Company will sell electricity (or more exactly, lease Projects) to private commercial and industrial companies, not to utilities. Although we select customers that we believe are financially strong and stable, it is always possible that one or more of our customers will default or even go bankrupt. In that case we would try to replace the defaulting customer with a paying customer, but there is no guaranty we will be able to do so and, in the meantime, the loss of revenue could cause us to default on our own obligations.

We Might Own Only a Small Number of Projects: If we are successful raising the full $50,000,000 we are trying to raise, the Company would likely acquire 15 – 20 Projects. The less money we raise the fewer Projects we will own. If we own only a small number of Projects, Investors will, by definition, be exposed to greater volatility and risk.

We Have Not Yet Acquired Any Projects: As of the date of this Offering Circular, the Company has not acquired any Projects and therefore has no revenue.

Possible Changes in Governmental Policies: The Projects depend on a Brazilian policy called Normative Resolution No. 482, which allows customers who generate solar power to offset electric costs at their locations within the same utility network. This policy could expire, phase-out over time, require renewal by the applicable authority, or become victims of political pressure. The regulator in Brazil responsible for electricity is expected to revisit its solar energy policies in 2020. The new policies could disfavor solar projects in general and our Projects in particular.

Delays in Connecting to Power Grid: Our Projects must be physically connected to the power grid, a process that involves both engineering and bureaucratic challenges. Delays are not uncommon. For example, the utility involved might be required to perform physical upgrades to allow for the safe and consistent generation, distribution, and/or transmission of electricity from the Project to the grid. Delays in the performance of the interconnecting utility’s obligations to make such grid upgrades can also impact the financial performance of the Projects.

Operational Risks: Our Projects are subject to operating and technical risks, including risk of mechanical breakdown, failure to perform according to design specifications, labor and other work interruptions and other unanticipated events that adversely affect operations. The success of each Project, once built, depends in part upon efficient operation and maintenance.

Construction and Development Risks: We expect to invest in Projects before construction is complete. Construction of any kind involves risks, including labor unrest, bad weather, design flaws, the unavailability of materials, fluctuations in the cost of materials, and labor shortages. Delays are common, which could adversely affect the economics of a Project.

Equipment Supply Constraints: The construction of renewable energy facilities relies on the availability of certain equipment that may be in limited supply, such solar modules, trackers, inverters and monitoring systems. Most of this equipment comes from China. There is no guarantee that the production of this equipment will match demand and this may adversely impact our ability to build Projects.

Risks Associated with Investments Outside the U.S.: All of our Projects will be in Brazil. Projects outside the United States jurisdictions are subject to certain risks that generally do not apply to investments within the United States. Such risks include the following:

Foreign Currency Exposure: The customer contracts entered into by the Projects will be denominated in Brazilian Real. Contracts denominated in Real will be subject to fluctuations in the exchange rates, which could hurt (or help) our total returns. While we might be able to hedge our foreign currency exposure to some degree, such hedging may be expensive and may not be entirely effective.

Imprecise Language Translations: All of our legal contracts in Brazil will be written in both English and Portuguese. Given that these languages have different historical and cultural roots, it is possible that some of the materials or proceedings may not directly translate across languages and any deviation, especially with respect to some of the more technical terms or work involved, may cause disruptions or misunderstandings that may negatively impact our business.

Risks Upon Disposition of Investments: When the Company sells a Project, we might be required to make representations about the business and financial affairs of the Project, and to indemnify the purchaser if our representations prove to be inaccurate or misleading. These arrangements may result in contingent liabilities, which might ultimately require Investors to return some or all of the distributions they have received.

Regulatory Risks: All of our Projects will be subject to extensive regulatory requirements, including those imposed by environmental, safety, labor and other regulatory and political authorities. These regulatory requirements will impose substantial costs on the Projects. Further, should any Project fail to comply with one or more regulatory requirements, it could result in substantial fines and penalties and even a shutdown of the Project.

Unavailability of Insurance Against Certain Catastrophic Losses: Certain losses of a catastrophic nature, such as earthquakes, wars, terrorist attacks or other similar events, may be either uninsurable or insurable at such high rates that to maintain such coverage would cause an adverse impact on the related Project. As a result, not all Projects may be insured against all possible risks. If a major uninsured loss occurs, the Company could lose both the amount it invested in and anticipated profits from the affected Project(s).

Potential Environmental Liability: Of course, protecting the global environment from fossil fuels is one of the main goals of solar energy projects. Nevertheless, our Projects, like any large-scale physical plant, could cause environmental contamination under some circumstances. Further, we could be found liable for environmental contamination that occurred before our Project was built. The cost of remediation and penalties could be very large.

Reliance on Suppliers: We rely heavily on a handful of suppliers for the components of our Projects. Should any of these suppliers go out of business, increase prices, or refuse to deal with us, our business could be damaged.

Liability for Personal Injury and Damage to Property: The Company could be held liable for accidents and injuries at our Projects. We will carry insurance to protect against the potential losses, but our insurance might not be adequate.

No Offering Minimum: If the Company raises the entire $50,000,000 we are trying to raise in the Offering, we will be able to acquire approximately 20 Projects, even if we don’t borrow any money. However, we will begin to spend the money we raise in the Offering as soon as we are able to finance just three Projects. As a result, an early Investor could own a far less diversified portfolio of Projects than he, she, or it expected.

We Might Raise More than $50,000,000: Under Regulation A, the Company is allowed to raise a maximum of $50,000,000 each year. Should we raise the full $50,000,000 we are trying to raise, we might decide to raise more, in a subsequent year. In that case an early Investor could own a much larger portfolio of Projects than he, she, or it expected.

Global or National Economic Conditions: An economic slowdown in Brazil could affect our customers and therefore our Projects.

Risks from COVID-19: As of the date of this Offering Circular, the world economy is suffering the sharpest and most severe slowdown since at least the Great Depression, and possibly in history. Despite action by governments and central banks, many experts believe the world faces a prolonged, deep recession if not a depression, with unemployment spiking to 20% or higher and large swaths of the economy shut down. We have no way of knowing how severely COVID-19 will affect our business. At a minimum we expect it to reduce demand for energy and therefore affect prices.

No Participation in Management: Investors will have no voting rights and no right to participate in the management of the Company or the Projects. Instead, the Company’s management will make all decisions. You will have the ability to replace our management team only under very limited circumstances, as described in “Summary of LLC Agreement and Authorizing Resolution – Management.” These very limited circumstances do not include just doing a bad job.

Reliance on Management: The success of the Company and its Projects will depend in part on the skills of our management team. If a key member of our management team resigned, died, or became ill, the Company and its Investors could suffer.

Sale of Other Securities: In this Offering, the Company is selling Class A Investor Shares for $1 per share. However, the Company could at any time sell other Class A Investor Shares or other classes of securities to raise additional capital. A different class of securities could have greater rights than those associated with the Class A Investor Shares, including but not limited to preferential rights to distributions.

Limitations on Rights in Investment Agreement: To purchase Class A Investor Shares, you are required to sign our Investment Agreement. The Investment Agreement will limit your rights in several important ways if you believe you have claims against us arising from the purchase of your Class A Investor Shares:

Forum Selection Provision: Our Investment Agreement and our LLC Agreement both provide that disputes will be handled solely in the state or federal courts located in Delaware. We included this provision primarily because (i) the Company is organized under Delaware law, (ii) Delaware courts have developed significant expertise and experience in corporate and commercial law matters and investment-related disputes (which typically involve very complex legal questions), particularly with respect to alternative entities (such as LLCs), and have developed a reputation for resolving disputes in these areas in an efficient manner, and (iii) Delaware has a large and well-developed body of case law in the areas of corporate and alternative entities law and investment-related disputes, providing predictability and stability for the Company and its Investors. This provision could be unfavorable to an Investor to the extent a court in a different jurisdiction would be more likely to find in favor of an Investor or be more geographically convenient to an Investor. It is possible that a judge would find this provision unenforceable and allow an Investor to file a lawsuit in a different jurisdiction.

Section 27 of the Exchange Act provides that Federal courts have exclusive jurisdiction over lawsuits brought under the Exchange Act, and that such lawsuits may be brought in any Federal district where the defendant is found or is an inhabitant or transacts business. Section 22 of the Securities Act provides that Federal courts have concurrent jurisdiction with State courts over lawsuits brought under the Securities Act, and that such lawsuits may be brought in any Federal district where the defendant is found or is an inhabitant or transacts business. Investors cannot waive our (or their) compliance with Federal securities laws. Hence, to the extent the forum selection provisions of the Investment Agreement or the LLC Agreement conflict with these Federal statutes, the Federal statutes would prevail.

Waiver of Right to Jury Trial: Our Investment Agreement and our LLC Agreement both provide that legal claims will be decided only by a judge, not by a jury. The provision in the LLC Agreement will apply not only to an Investor who purchases Class A Investor Shares in the Offering, but also to anyone who acquires Class A Investor Shares in secondary trading. Having legal claims decided by a judge rather than by a jury could be favorable or unfavorable to the interests of an owner of Class A Investor Shares, depending on the parties and the nature of the legal claims involved. It is possible that a judge would find the waiver of a jury trial unenforceable and allow an owner of Class A Investor Shares to have his, her, or its legal claim decided by a jury. In any case, the waiver of a jury trial in both the Investment Agreement and the LLC Agreement do not apply to claims arising under the Federal securities laws.

Conflicts of Interest: The interests of the Company and its management could conflict with your interests in a number of important ways, including these:

Risk of Failure to Comply with Securities Laws: The current Offering relies on an exemption under Regulation A of the Securities and Exchange Commission. We have relied on the advice of securities lawyers and believe we qualify for the exemption. If we did not qualify, we could be liable to penalties imposed by the federal government and state regulators, as well as to lawsuits from investors.

No Market for the Class A Investor Shares; Limits on Transferability: There are two obstacles to selling or otherwise transferring your Class A Investor Shares:

Risk Associated with Escrow Account: When you invest, your money will be held in an escrow account. Although the escrow account will be held at banks insured by the FDIC, the amount in any such account could exceed the FDIC limits. If the bank holding the escrow account became insolvent in that situation, you could lose some or all of your money.

Corporate Governance Risk: As a non-listed company conducting an exempt offering pursuant to Regulation A, we are not subject to a number of corporate governance requirements that an issuer conducting a registered offering or listed on a national stock exchange would be. For example, we do not have (i) a board of directors of which a majority consists of “independent” directors under the listing standards of a national stock exchange, (ii) an audit committee composed entirely of independent directors and a written audit committee charter meeting a national stock exchange's requirements, (iii) a nominating/corporate governance committee composed entirely of independent directors and a written nominating/corporate governance committee charter meeting a national stock exchange's requirements, (iv) a compensation committee composed entirely of independent directors and a written compensation committee charter meeting the requirements of a national stock exchange, and (v) independent audits of our internal controls.

We Are an “Emerging Growth Company” Under the JOBS Act: Today, the Company qualifies as an “emerging growth company” under the JOBS Act of 2012. If the Company were to become a public company (e.g., following a registered offering of its securities) and continued to qualify as an emerging growth company, it would be able to take advantage of certain exemptions from the reporting requirements under the Securities Exchange Act of 1934 and exemptions from certain investor protection measures under the Sarbanes Oxley Act of 2002. Using these exemptions could benefit the Company by reducing compliance costs but could also mean that Investors receive less information and fewer protections than they would otherwise. However, these exemptions – and the status of the Company as an “emerging growth company” in the first place – will not be relevant unless and until the Company becomes a public reporting company.

The Company has elected to delay complying with any new or revised financial accounting standard until the date that a company that is not an “issuer” (as defined under section 2(a) of the Sarbanes-Oxley Act of 2002 is required to comply with such new or revised accounting standard, if such standard also applies to companies that are not issuers. As a result, owners of Class A Investor Shares might not receive the same disclosures as if the Company had not made this election.

Breaches of Security: It is possible that our systems or the systems of third-party service providers would be “hacked,” leading to the theft or disclosure of confidential information you have provided to us. Because techniques used to obtain unauthorized access or to sabotage systems change frequently and generally are not recognized until they are launched, we and our vendors may be unable to anticipate these techniques or to implement adequate defensive measures.

The Foregoing Are Not Necessarily The Only Risks Of Investing
Please Consult With Your Professional Advisors

OUR COMPANY AND BUSINESS

Overview

The Company was formed to acquire, develop, and operate solar energy projects in Brazil (each a “Project”). The Projects will be rented to credit-worthy commercial and industrial businesses pursuant to long-term (10–20 year) contracts, which we expect to provide a stable and predictable stream of net cash flow.

The Company has not yet invested in any Projects, but has identified three Projects we are likely to invest in. These are described in “Our First Projects” on page 26.

Because the Company has not yet invested in any Projects, it has no cash flow.

Corporate Structure

The Company is a Delaware limited liability company.

Projects will be owned by special-purpose entities (each, an “SPE”). We currently anticipate that each SPE will be organized as Brazilian Sociedade Anônima, the Brazilian equivalent of a U.S. corporation. Under Brazilian law, the assets and liabilities of a Sociedade Anônima are distinct. Thus, the liabilities of a Project held in one SPE will not affect the assets of another Project held in a different SPE.

Typically the Company will own 100% of each SPE, although there could be instances where the Company is a partner in the SPE with another party, such as the developer of the Project or the former owner. In all cases the Company will exercise complete management control over the SPE.

The Company and all of its owners are subject to a Limited Liability Company Agreement dated May 18, 2020, which governs the ownership, management, and operation of the Company (the “LLC Agreement”). The key terms of the LLC Agreement are summarized in “Summary of LLC Agreement and Authorizing Resolution” on page 43, and a copy of the LLC Agreement is attached as Exhibit 1A-2B.

Management

The Company will be managed by Energea Global, LLC, a Delaware limited liability company (“Energea Global” or the “Manager”). The Manager will exercise complete control of the Company and the Projects. For example, the Manager will select each Project, negotiate the terms of the Project Rental Contract for each Project, as well as the maintenance contracts for each Project, decide whether to borrow money and, if so, how much, oversee the design and construction of each Project, decide whether and when to sell Projects, decide how much capital to raise through the sale of Class A Investor Shares, and decide how and whether to raise capital through other means.

Investors will have the right to remove the Manager only for narrowly defined “cause,” and then only after following a procedure set forth in the LLC Agreement. See “Summary of LLC Agreement and Authorizing Resolution” on page 43.

The Manager is, in turn, owned and controlled by Mike Silvestrini and Chris Sattler. See “Our Management Team” on page 54.

The Crisis of Climate Change

Climate change is no longer a theory but a fact, in plain view.

As bad as things seem today, they are going to get much worse very quickly unless we act. According to the United Nations Intergovernmental Panel on Climate Change (the “IPCC”), we have until 2030 before rising temperatures cause a climate catastrophe: worse and more frequent cataclysmic weather events, the devastation of many natural plant and animal habitats leading to mass extinctions and the destruction of important ecosystems, interruptions of the global food supply chain, and poverty for hundreds of millions of human beings¹.

To put it simply, unless we take dramatic action soon, we will harm the earth and all of its inhabitants irreparably.

The rapid rise in greenhouse gas (“GHG”) emissions is a significant culprit in our crisis. As its name implies, GHG emissions have a “greenhouse effect” on the earth’s climate, allowing sunlight to pass through the atmosphere but preventing heat from escaping.

The single biggest driver in the increase in GHG emissions is the dramatic increase in carbon dioxide emissions. According to the United States Environmental Protection Agency, about three-quarters (76%) of global man-made GHG emissions come from carbon dioxide emissions².

The sharp rise in carbon dioxide emissions (and in turn GHG emissions), is primarily a post-World War II phenomenon. Between 1850 and 1940 fewer than 5 trillion tons of carbon dioxide emissions were released per year. Beginning in 1950, global carbon dioxide emissions began to increase dramatically to more than 30 trillion tons each year between 2010 and 2020. By 2030, carbon emissions are projected to exceed 38 trillion tons per year and will be more than 42 trillion by 2040³.

The global energy industry is by far the largest industry contributor to GHG emissions. According to the World Resources Institute, the energy industry accounts for 72% of all global GHG emissions, followed by agriculture (11%), land-use change/forestry (6%), and industrial processing (6%)⁴. Within the energy footprint, electricity and heat constitute the biggest source of GHG emissions (constituting 31% of the energy industry’s footprint), with transportation (15%) and manufacturing/construction a distant second and third respectively⁵. Thus, if we can change the way we produce energy, we can dramatically decrease the amount of carbon dioxide and GHGs being released into the atmosphere, and in turn prevent the global climate crisis described by the IPCC.

For example, for every megawatt of electrical capacity we can transfer from a coal-burning plant to a solar project, we keep approximately 1,000 tons of carbon out of the atmosphere every year.

Today, renewable energy sources remain well behind their higher-emitting fossil fuel peers. In 2016, renewable energy sources made up only about one-quarter (24%) of global electricity generation, with the United States gaining even less of its electricity production (17%) than its international peers⁶. The good news is that renewable energies are the fastest-growing energy source in the United States, having increased more than one hundred (100%) percent between 2000 and 2018⁷.

Within the domestic renewable energy portfolio, solar energy makes up a small but quickly growing portion of U.S. electricity generation⁸. In 2018, solar energy came in a distant third (about 3%) to hydropower (7%) and wind power (6.6%) in terms of total U.S. electricity generation. However, solar energy is by far the fastest growing domestic renewable energy source and solar is projected to make up nearly half (48%) of all domestic renewable energy electricity production by 2050⁹. This rapid rate of growth, combined with the incredible size of the global and domestic energy generation market and the solar industry’s currently small footprint within that energy space, makes solar well positioned to lead the climate change fight well into the next century.

The Economics of Solar Power in Brazil

The cost of electricity in Brazil has risen for several reasons:

We believe the cost of electricity in Brazil will continue to rise for the foreseeable future.

At the same time the cost of electricity is rising, the cost of building solar projects is falling. When the principals of our Manager built their first solar projects in 2007, the cost was approximately $8.00 per watt. Today, projects are built for as little as $0.70 per watt, a cost reduction of more than 90%.

As a result of these trends, we are typically able to offer commercial and industrial customers savings of 20% - 40% on their electricity bills without the need for tax credits, grants, renewable energy credits, or other subsidies solar power once required. These customers might prefer solar power over power generated by fossil fuels because they care about the environment and/or want to fight climate change. But the economic savings speak for themselves.

Typical Project Characteristics

NOTE: Because Projects are located on land we control rather than on the customer’s site, if a customer defaults we can simply turn off the power and direct it elsewhere.

Thus, in most cases Investors are not exposed to any Project-level risks until all these conditions are satisfied. However, we might make exceptions for exceptionally promising Projects.

How We Find Projects – Development Companies

By and large, we find Projects in partnership with the many companies in Brazil focused on developing solar power projects, which we refer to as “Development Companies.” In fact, our Manager has an affiliate in Brazil, Energea do Brasil (“Energea Brazil”), which is itself a Development Company.

Our relationship with Development Companies can take a number of different forms. Sometimes a Development Company will not only identify a potential project, but also permit, engineer and construct it. Sometimes a Development Company will provide operations and maintenance support for a Project after it’s built. Sometimes a Development Company will sell us a Project Rental Contract and exit the Project entirely. In general, the Development Company is responsible for ensuring that all the conditions described in “Typical Project Characteristics – When We Invest in Projects” immediately above.

NOTE: Development Companies are compensated for their work and their risk. This may include a developer fee or a continued economic interest in the Project SPE. However, where a Project is originated through Energea Brazil, the Manager’s affiliate, Energea Brazil will cap the related-party development fee at 5% of the overall Project’s cost.

In general, there are two ways a solar power project is developed in Brazil:

We expect to use both approaches to identify Projects.

Leverage

The Company might (or might not) borrow money to invest in Projects, depending on the circumstances at the time. If the Company can raise money from Investors quickly enough in this Offering, we probably will not borrow. On the other hand, if we need to move quickly on a Project and have not yet raised enough capital in this Offering, we might make up the shortfall through borrowing. Our Manager will make this decision on an as-needed basis.

At the end of 2019 our Manager obtained from Quasar Asset Management LTDA a non-binding written commitment to lend up to 125,000,000 Brazilian real (roughly $25,000,000 U.S. dollars) to acquire solar projects. The commitment would become binding with respect to an individual project upon the execution of final loan documents for that project.

The Manager might draw upon this commitment to fund the acquisition of Projects for the Company or for other entities the Manager controls.

We are currently assuming that the first three Projects will be funded only with equity, not with debt.

Sale of the Projects

Currently, we plan to hold our Projects indefinitely, creating a reliable stream of cash flow for Investors. Should we decide to sell one or more Projects, however, our experience in the industry suggests that they could be sold for a profit:

Our Revenue and Expenses

Revenue

The revenue from our Projects will consist primarily of the payments we receive from customers under Project Rental Contracts and Project Operations and Maintenance Contracts.

Expenses

The principal expenses of our Projects will consist of:

Offices and Employees

The Company itself will not have offices or employees. Instead, our Manager will provide all services required to operate the Company (other than on-site construction, operation, and maintenance and other services provided by third parties), as well as the office space and equipment necessary to provide such services.

Factors Most Likely to Affect Our Business

The ability of the Company to conduct its business successfully depends on several critical factors:

PAST PERFORMANCE: GREENSKIES RENEWABLE ENERGY, LLC

Mike Silvestrini co-founded Greenskies Renewable Energy, LLC (“Greenskies”) with a $35,000 family loan in 2008. Under Mike’s leadership Greenskies:

Except for geography – the U.S. market versus the Brazilian market – the business of Greenskies is very similar to the business of the Company. The type and the size of solar project, the construction methods, the customer demographics, even the equipment itself will be nearly identical, not surprising given that sunlight and the technology for converting it to electricity are the same everywhere.

In 2007, when Greenskies was launched, solar projects cost approximately $8.00 per watt to build. Today, projects are built for as little as $0.67 per watt, a cost reduction of more than 90%. These economics make solar projects today that much more compelling than it has been previously.

CAUTION: Past performance does not guaranty future results. Even though Mr. Silvestrini was very successful with Greenskies, there are many reasons why the Company might not be successful, including all of those listed in “Risks of Investing” on page 9.

OUR FIRST PROJECTS

As of the date of this Offering Circular the Company does not own any Projects and therefore has no cash flow or revenues.

We expect to acquire the following three Projects first:

*We calculate the internal rate of return for the Project based on the anticipated cash flows from the Project. We assume that the Project will have a zero value at the expiration of the initial contract term. This is intentionally a conservative assumption. In almost all cases a Project will have some residual value, and sometimes a significant residual value. For example, we might enter into a new Project Rental Contract for the Project, even if at a lower rent.

**The land will be owned by Energea Real Estate Ltda, an affiliate of the Manager. The Company (actually the SPE for the Project) will pay the lowest rent permitted by law.

Our Manager, or an affiliate of our Manager in Brazil, controls each of these Projects. For each Project an SPE has been formed and the key contracts have been negotiated or are in the process of being negotiated. Ownership of the SPEs – and thus of the Projects – will be transferred to the Company upon satisfaction of the conditions described in “Our Company and Business – Typical Project Characteristics – When We Invest in Projects.” Our Manager expects these conditions to be satisfied, and therefore expects the Company to acquire the Projects.

For each Project we prepare a Project Summary and a Financial Memo. The Project Summary includes extensive information about the Project while the Financial Memo includes financial assumptions and financial projections captioned “Estimated Results of Operations.” The Project Summaries and Financial Memos for the three Projects above are attached as Appendices to this Offering Circular:

The Estimated Results of Operations for each Project are based principally on the Land Lease, Construction Contract, Project Rental Contract, Operations and Maintenance Contract, and Project Maintenance Contract for that Project, as such contracts have already been negotiated or as the Manager expects them to be negotiated. Together, these contracts establish most of the revenue and expense items for each Project, although items of revenue and expense can vary based on built-in adjustment mechanisms like consumer prices. See “Summary of Important Contracts.” Items reflected in the Estimated Results of Operations other than those reflecting the terms of these contracts are based on assumptions the Manager believes are reasonable.

If and when the Company acquires additional Projects, we will provide a Project Summary and a Financial Memo for each.

SECURITIES BEING OFFERED: THE CLASS A INVESTOR SHARES

Description of Securities

We are offering to the public up to $50,000,000 of Class A Investor Shares, which represent limited liability company interests in the Company. All of the rights and obligations associated with the Class A Investor Shares are set forth in:

Price of Class A Investor Shares

Initially, we will offer the Class A Investor Shares at $1.00 per Class A Investor Share. During the term of this Offering, we expect to increase or decrease the price per Class A Investor Share to reflect changes in the value of our Projects. Changes in the price of the Class A Investor Shares will be reflected in a supplement to this Offering Statement filed with the SEC.

The value of our Projects will be determined by the Manager in its sole discretion using the comprehensive financial model it has developed for the Projects, projecting their cost and revenue (the “Financial Model”). In general, the Financial Model determines the value of Projects, and thus the price of Class A Investor Shares, is based on the current present value of Projects calculated using Microsoft Excel. Thus, factors that could cause changes to the price of Class A Investor Shares include (i) the addition of new Projects, (ii) changes in the anticipated revenue or costs associated with a Project, and (iii) the passage of time (because the present value of a future cash flow increases as the future cash flow gets closer).

Voting Rights

Owners of the Class A Investor Shares – that is, Investors – will have no right to vote or otherwise participate in the management of the Company. Instead, the Company will be managed by the Manager exclusively.

Distributions

We intend to make distributions periodically, as conditions permit. The order of distributions will be governed by the Company’s LLC Agreement and by the Authorizing Resolution.

We divide distributions into two categories:

Distributions of ordinary operating cash flow will be made as follows:

EXAMPLE: For the sake of simplicity, suppose the portfolio consists of one hypothetical Project with a projected lifespan of five years, with the following projected cost and positive cash flows:

Those cash flows yield a Project IRR of 16.35%.

To calculate the Adjusted Operating Cash Flow, we find a single percentage which, when multiplied by each operating cash flow, yields an IRR of 7% rather than 16.35%. For this hypothetical Project, that single percentage is 79.758%. We multiply each positive cash flow by 79.758%:

Thus, for this hypothetical Project (and portfolio), Investors would receive the first $2,791.53 of operating cash flow in Year 1, the first $1,993.95 in Year 2, and so forth. If the Project actually generated $3,500 of operating cash flow in Year 1, as projected, then Investors would receive the first $2,791.53 and the balance, or $708.47, would be divided 70%, or $495.93, to Investors and 30%, or $212.54, to the Manager.

Distributions of the net proceeds from a capital transaction will be made in the following order or priority:

We refer to the amounts distributed to the Manager as its “Promoted Interest.”

We expect to make distributions of ordinary operating cash flow on a monthly basis. Distributions of the net proceeds from capital transactions will be made, if at all, upon the occurrence of a capital transaction.

Whether to distribute operating cash flow or capital proceeds, and how much to distribute, are in the sole discretion of the Manager. No returns are guaranteed. Investors will receive distributions only if we are able to generate a profit from the business.

Distributions in Liquidation

Distributions made in liquidation of the Company will be made in the manner described above, depending on whether the distributions consist of ordinary operating cash flow or net capital proceeds.

Preemptive rights

The holders of the Class A Investor Shares will not have preemptive right means. That means that if the Company decides to issue securities in the future, the holders of the Class A Investor Shares will not have any special right to buy those securities. Of course, the Company might offer the new securities to the holders of the Class A Investor Shares even though it doesn’t have to.

Liability to Make Additional Contributions

Once an Investor pays for his, her, or its Class A Investor Shares, the Investor will have no obligation to make further contributions to the Company. However, there could be circumstances where an Investor who has received distributions with respect to his, her, or its Class A Investor Shares is required to return part or all of the distribution.

How We Decide How Much To Distribute

To decide how much to distribute, we start with the revenue from each Project from our Project Rental Contracts and our Operations and Maintenance Contracts, add miscellaneous income like interest, add any proceeds we have received from the sale or refinancing of Projects, and then subtract our actual expenses of operating the Projects, including salaries, rent, debt service, asset management fees, marketing costs, taxes, legal and accounting fees, travel expenses, commissions, and debt service. Finally, depending on the circumstances at the time, we decide how much should be held in reserve against future contingencies. The amount we distribute is therefore our revenue, minus our expenses, minus the reserve amount.

The revenue and expenses of our Projects will be denominated in REAL, the Brazilian currency, while our distributions to Investors will be in U.S. dollars. If we believe the value of the REAL is likely to climb relative to the dollar in the short term, we might delay a distribution and thereby take advantage of the anticipated change.

Withholding

In some situations, we might be required by law to withhold taxes and/or other amounts from distributions made to Investors. The amount we withhold will still be treated as part of the distribution. For example, if we distribute $100 to an Investor and are required to withhold $10 in taxes, for our purposes the Investor be treated as having received a distribution of $100 even though only $90 was deposited in the Investor’s bank account.

No Guaranty

We can only distribute as much money as we have. There is no guaranty that we will have enough money, after paying expenses, to distribute enough to pay a 7% annual return to Investors or even to return all of their invested capital.

Transfers

Investors may freely transfer their Class A Investor Shares, but only after providing the Manager with written assurance that (i) the transfer is not required to be registered under the Securities Act of 1933, and (ii) the transferor or the transferee will reimburse the Company for expenses incurred in connection with the transfer.

However, an Investor who wants to sell his, her, or its Class A Investor Shares must first offer them to the Manager.

Mandatory Redemptions

The Manager may require an Investor to sell his, her, or its Class A Investor Shares back to the Company:

If an Investor’s Class A Investor Shares are purchased by the Company as provided above, the price will be equal to 90% of the then-current value of such Class A Investor Shares as determined by the Company in accordance with the Financial Model.

The purchase price will be paid by wire transfer or other immediately available funds.

Limited Right of Redemption

An Investor who has owned Class A Investor Shares for at least one year may ask the Company to purchase, or arrange for the purchase, of all or a portion of his, her, or its Class A Investor Shares. Upon receipt of such a request, the Manager must use commercially reasonable efforts to arrange for the purchase, although there is no guaranty that the necessary funds will be available or that a buyer can be found. If the Manager is not able to purchase or arrange for the purchase of the Class A Investor Shares, the Investor may either rescind or maintain the request.

In seeking to accommodate a request from an Investor, the Manager is not required to do any of the following:

If an Investor’s Class A Investor Shares are purchased by the Company as provided above, the price will be equal to the then-current value of such Class A Investor Shares as determined by the Company in accordance with the Financial Model.

The purchase price will be paid by wire transfer or other immediately available funds.

If more than one Investor asks the Manager to purchase or arrange for the purchase of Class A Investor Shares, the Manager will consider the requests in the order received.

Liquidity – secondary Market

The Company currently intends to create a secondary market for the Class A Investor Shares, to provide liquidity for Investors, although we have not decided the form such a secondary market will take. For example, we might have the Class A Investor Shares listed on an existing exchange or we might create our own “alternative trading system” for the Class A Investor Shares.

However, our current plans could change, and there is no guaranty that a secondary market for the Class A Investor Shares will ever exist. Moreover, even if a secondary market exists, there might not be enough buyers and sellers to provide meaningful liquidity.

Rights of Common Shares

Immediately following the Offering the Company will have two classes of securities outstanding: Class A Investor Shares and Common Shares. Investors will own all the Class A Investor Shares while the Manager will own all the Common Shares. The principal rights associated with the Common Shares are as follows:

LIMIT ON AMOUNT A NON-ACCREDITED INVESTOR CAN INVEST

As long as you’re at least 18 years old, you can invest in this Offering. But if you’re not an “accredited” investor, the amount you can invest is limited by law.

Under 17 CFR §230.501, a regulation issued by the Securities and Exchange Commission, the term “accredited investor” means:

If you fall within any of those categories, then you can invest as much as you want. If you don’t fall within any of those categories, then the most you can invest in this Offering is the greater of:

These limits are imposed by law, not by us.

When you go to our website, www.energea.com, we will ask whether you’re an accredited investor. If you aren’t, then we’ll ask about your annual income and net worth.

SUMMARY OF IMPORTANT CONTRACTS

Introduction

We use five main contracts:

There are two versions of each of these contracts, one in English and the other in Portuguese, the national language of Brazil.

Although the economic terms will differ from Project to Project, the rights and obligations of the parties will generally be consistent across our portfolio of projects, and indeed are generally consistent throughout the solar industry in Brazil. We have summarized below the principal terms of what expect to be the “typical” version of each contract.

Typical Land Lease

The principal terms are as follows:

Typical Construction Contract

The principal terms are as follows:

Typical Project Rental Contract

The principal terms are as follows:

Typical Operations and Maintenance Contract

The principal terms are as follows:

Typical Project Maintenance Contract

The principal terms are as follows:

SALE AND DISTRIBUTION OF SECURITIES

We are offering to sell up to $50,000,000 of Class A Investor Shares to the public.

The Offering will begin as soon as our Offering Statement is “qualified” by the SEC and will end on the sooner of (i) a date determined by the Company, or (ii) the date the Offering is required to terminate by law.

Only the Company is offering securities in this Offering. None of our existing officers, directors, or stockholders is offering or selling any securities.

We are not using an underwriter or broker to sell the Class A Investor Shares. We are selling Class A Investor Shares only through our website, located at www.EnergeaGlobal.com, which we refer to as the “Site.”

We are not paying commissions to anybody for selling the Class A Investor Shares.

We reserve the right to reject any subscription to purchase Class A Investor Shares in this Offering in whole or in part and for any reason (or no reason). If we reject your subscription, we will return all your money without interest or deduction.

After the Offering has been “qualified” by the Securities and Exchange Commission, we intend to advertise the Offering using the Site and through other means, including public advertisements and audio-visual materials, in each case only as we authorize and in compliance with 17 CFR §251(d)(1)(iii), which provides that any written offers must be accompanied with or preceded by the most recent offering circular filed with the SEC. Although these materials will not contain information that conflicts with the information in this Offering Circular and will be prepared with a view to presenting a balanced discussion of risk and reward with respect to the Class A Investor Shares, our advertising materials will not give a complete understanding of this Offering, the Company, or the Class A Investor Shares and are not to be considered part of this Offering Circular. The Offering is made only by means of this Offering Circular and prospective Investors must read and rely on the information provided in this Offering Circular in connection with their decision to invest in Class A Investor Shares.

HOW TO INVEST

To buy Class A Investor Shares, go to the Site and follow the instructions. We will ask for certain information about you, including:

We will also ask you to sign our Investment Agreement, a copy of which is attached as Exhibit 1A-4.

The minimum investment is $500. You will pay for your Class A Investor Shares using one of the options described on the Site.

The information you submit, including your signed Investment Agreement, is called your “subscription.” We will review your subscription and decide whether to accept it. We have the right to accept or reject subscriptions in our sole discretion, for any reason or for no reason.

When you invest, your money will be held in an escrow account with a third party until we review your subscription and decide whether to accept it. When and if we have confirmed that your subscription is complete and decided to accept your subscription, we will release your money from the escrow account to the Company on the first day of the month following the month in which you made the investment. If we decide not to accept your subscription, we will return your money to you.

Once we have accepted your subscription, we will notify you by email and the investment process will be complete. We will also notify you by email if we do not accept your subscription, although we might not explain why.

We will not issue you a paper certificate representing your Class A Investor Shares.

Anyone can buy Class A Investor Shares. We do not intend to limit investment to people with a certain income level or net worth, although there are limits on how much non-accredited investors may invest in this Offering. For more information, please refer to “Limit On Amount a Non-Accredited Investor Can Invest” starting on page 34.

USE OF PROCEEDS

We expect the Offering itself to cost about $100,000, including legal and accounting fees – principally the cost of preparing this Offering Circular, having the Offering “qualified” by the SEC, and filing notices with states where our investors live, as required by state law. We also expect to spend at least $100,000 marketing the Offering. Otherwise, all of the proceeds of the Offering, no matter how much we raise, will be used to acquire Projects.

We might acquire Projects using the Manager’s capital before we have raised enough capital from Investors. In that case we will replace the Manager’s capital with capital from Investors as soon as we raise it. To the extent the Manager or its affiliates invest capital, they will do so on the same terms as other Investors.

We are not paying commissions to underwriters, brokers, or anybody else for selling or distributing the Class A Investor Shares. Because we are not paying any commissions, more of your money can go to work for you. In some cases, retirement custodians, investment advisers, and other intermediaries will offer to invest on behalf of their clients. In such cases, the custodian, adviser or intermediary will be paid a fee from their client’s invested funds. In such cases, the client (rather than the Company) is paying those fees.

SUMMARY OF LLC AGREEMENT AND AUTHORIZING RESOLUTION

The Company as a whole is governed by an agreement captioned “Limited Liability Company Agreement” dated January 23, 2020. We refer to this as the “LLC Agreement.”

The Class A Investor Shares being offered in this Offering were created when the Manager adopted a resolution pursuant to section 3.1 of the LLC Agreement. We refer to this as the “Authorizing Resolution.”

The following summarizes some of the key provisions of the LLC Agreement and the Authorizing Resolution. This summary is qualified in its entirety by the LLC Agreement itself, which is included as Exhibit 1A-2B, and by the Authorizing Resolution itself, which is included as Exhibit 1A-2C.

Formation and Ownership

The Company was formed in Delaware on January 23, 2020 pursuant to the Delaware Limited Liability Company Act.

Under the LLC Agreement, ownership interests in the Company are referred to as “Shares,” while the owners are referred to as “Members.”

Immediately before this Offering, the only owner of the Company was the Manager. Investors who buy Class A Investor Shares in the Offering will become owners, and the Company might admit other owners in the future.

Shares and Ownership

The interests in the Company are denominated by 501,000,000 “Shares,” consisting of 1,000,000 “Common Shares” and 500,000,000 “Investor Shares.” The Manager may further divide the 19,000,000 Investor Shares into one or more series, by adopting one or more authorizing resolutions. Anyone owning Investor Shares is referred to in the LLC Agreement as an “Investor Member.”

The Manager adopted the Authorizing Resolution to create the Class A Investor Shares. Any Investor who buys Class A Investor Shares in the Offering will be an “Investor Member” under the LLC Agreement.

All of the Common Shares of the Company are owned by the Manager. The Class A Investor Shares will be owned by Investors and are the subject of this Offering. By adopting other authorizing resolutions, the Manager may create, offer, and sell other series of Investor Shares in the future, which could have rights superior to the rights of the Class A Investor Shares.

Management

The Manager has complete discretion over all aspects of the business conducted by the Company. For example, the Manager may (i) admit new members to the Company; (ii) enter into contracts on behalf of the Company; (iii) borrow money; (iv) acquire and dispose of assets; (v) determine the timing and amount of distributions to Members; (vi) create new classes of limited liability company interests; (vii) determine the information to be provided to the Members; (viii) grant liens and other encumbrances on the assets of the Company; (ix) and dissolve the Company.

Investors who purchase Class A Investor Shares will not have any right to vote on any issue other than certain amendments to the LLC Agreement, or to remove the Manager.

The Manager can be removed for “cause” under a procedure set forth in section 5.6 of the LLC Agreement.

The term “cause” includes:

A vote to remove the Manager for cause must be approved by Investor Members owning at least two-thirds of the outstanding Investor Shares. Whether “cause” exists would then be decided in arbitration proceedings conducted under the rules of the American Arbitration Association, rather than in a court proceeding.

These provisions are binding on every person who acquires Class A Investor Shares, including those who acquire Class A Investor Shares from a third party, i.e., not from the Company.

Exculpation and Indemnification of Manager

The LLC Agreement protects the Manager and its employees and affiliates from lawsuits brought by Investors. For example, it provides that the Manager will not be responsible to Investors for mistakes, errors in judgment, or other acts or omissions (failures to act) as long as the act or omission was not the result of the Manager’s (i) willful misfeasance, (ii) bad faith, or (iii) gross negligence in the performance of, or reckless disregard of, its duties under the LLC Agreement. This limitation on the liability of the Manager and other parties is referred to as “exculpation.”

The LLC Agreement also requires the Company to indemnify (reimburse) the Manager, its affiliates, and certain other parties from losses, liabilities, and expenses they incur in performing their duties. For example, if a third party sues the Manager on a matter related to the Company’s business, the Company would be required to indemnify the Manager for any losses or expenses it incurs in connection with the lawsuit, including attorneys’ fees. However, this indemnification is not available where a court or other juridical or governmental body determines that the Manager or other person is not entitled to be exculpated under the standard described in the preceding paragraph.

Notwithstanding the foregoing, no exculpation or indemnification is permitted to the extent such exculpation or indemnification would be inconsistent with the requirements of federal or state securities laws or other applicable law.

The detailed rules for exculpation and indemnification are set forth in section 6.2 of the LLC Agreement.

Obligation to Contribute Capital

Once an Investor pays for his, her, or its Class A Investor Shares, he, she, or it will not be required to make any further contributions to the Company. However, if an Investor has wrongfully received a distribution he, she, or it might have to pay it back.

Personal Liability

No Investor will be personally liable for any of the debts or obligations of the Company.

Distributions

The manner in which the Company will distribute its available cash is described in “Securities Being Offered – Distributions” on page 28.

Transfers and First Right of Refusal

In general, Investors may freely transfer their Class A Investor Shares. However, if an Investor wants to sell Class A Investor Shares, the Investor must first offer the Class A Investor Shares to the Manager.

Death, Disability, Etc.

If an Investor who is a human being (as opposed to an Investor that is a legal entity) should die or become incapacitated, the Investor or his, her or its successors will continue to own the Investor’s Class A Investor Shares.

Fees to Manager and Affiliates

The Company will pay certain management fees and other fees to the Manager, as summarized in “Management Fees” on page 58.

Mandatory Redemption

The Manager may cause the Company to redeem (purchase) the Class A Investor Shares owned by an Investor in any of three circumstances (in effect kicking the Investor out of the deal) as described in “Securities Being Offering – Mandatory Redemptions” on page 32.

“Drag-Along” Right

If the Manager wants to sell the business conducted by the Company, it may affect the transaction as a sale of the Project owned by the Company or as a sale of all the Shares in the Company. In the latter case, Investors will be required to sell their Class A Investor Shares as directed by the Manager, receiving the same amount they would have received had the transaction been structured as a sale of assets.

Electronic Delivery

All documents, including all tax-related documents, will be transmitted by the Company to Investors via electronic delivery.

Amendment

The Manager may amend the LLC Agreement unilaterally (that is, without the consent of anyone else) for a variety of purposes, including to:

An amendment that has, or could reasonably be expected to have, an adverse effect on Investors, requires the consent of the Manager and Investors holding a majority of the Class A Investor Shares.

An amendment that would require an Investor to make additional capital contributions or impose personal liability on an Investor requires the consent of the Manager and each affected Investor.

Information Rights

Within 120 days after the end of each fiscal year of the Company, we will provide Investors with (i) a statement showing in reasonable detail the computation of the distributions made by the Company, and (ii) audited financial statements of the Company.

In addition, each year the Company will provide Investors with a detailed statement showing:

In each case, the detailed statement will describe the services performed and the amount of compensation paid.

As a “tier 2” issuer under Regulation A, the Company will also be required to provide investors with additional information on an ongoing basis, including annual audited financial statements, annual reports filed on SEC Form 1-K, semiannual reports filed on SEC Form 1-SA, special financial reports filed on SEC Form 1-K, and current reports on SEC Form 1-U. If, however, our Class A Investor Shares are held “of record” by fewer than 300 persons, these reporting obligations could be terminated.

A Member’s right to see additional information or inspect the books and records of the Company is limited by the LLC Agreement.

U.S. AND BRAZILIAN TAXES

The following summarizes the most significant Brazilian taxes that will be imposed on the SPEs and the Company, as well as the Federal income tax consequences of acquiring Class A Investor Shares. This summary is based on the current tax laws of Brazil, the current U.S. Internal Revenue Code (the “Code”), the current regulations issued by the Internal Revenue Service (“Regulations”), and current administrative rulings and court decisions, all as they exist today. All of these tax laws could change in the future.

This is only a summary, applicable to a generic Investor. Your personal situation could differ. We encourage you to consult with your own tax advisor before investing.

Brazilian Taxes

Brazilian Tax System Generally

Like the United States, taxes in Brazil are imposed at the federal, state, and local level.

The federal government will impose the following taxes on each SPE:

The SPEs will be entitled to depreciation deductions with respect to certain equipment.

At the state level, each SPE will be subject to a tax on purchased goods (e.g., solar equipment). The ICMS rates vary by state but will typically be imposed at 18%.

At the local level, many municipalities impose a tax on revenues from services provided (e.g., the services an SPE will provide to customers under a Project Operation and Maintenance Agreement). These taxes are typically imposed at a rate of 5%.

NOTE: Brazil does not impose a tax on the Company itself or on Investors, nor does it require SPEs to withhold any taxes from distributions to the Company investor (Company or Individual) for permanent investors.

U.S. Federal Income Taxes

Classification as a Partnership

The Company will be treated as a partnership for federal income tax purposes. As a partnership, the Company will not itself be subject to federal income taxes. Instead, each Investor will be required to report on his, her, or its federal income tax return a distributive share of the Company’s income, gains, losses, deductions and credits for the taxable year, without regard to whether the Investor receives any distributions. Each Investor’s distributive share of such items will be determined in accordance with the LLC Agreement.

Each Investor will receive an IRS Schedule K-1 each year, showing the Investor’s distributive share of the Company’s income, gains, losses, deductions and credits. We will try to have K-1s to Investors no later than February 28^th.

Taxation of Dividends

The income of the Company will consist primarily of dividends received from our SPEs. Because our SPEs will be foreign corporations, these dividends will be “non-qualified dividends” within the meaning of the Code and therefore subject to tax at ordinary income tax rates (“qualified dividends,” including dividends from most U.S. corporations, are subject to tax at preferential rates).

Foreign Tax Credit

Investors might be entitled to credits for taxes paid by the SPEs in Brazil.

Deduction of Losses

The Company is not expected to generate significant losses for federal income tax purposes. If it does generate losses, each Investor may deduct his, her, or its allocable share subject to the basis limitations of Code section 704(d), the “at risk” rules of Code section 465, and the “passive activity loss” rules of Code section 469. Unused losses generally may be carried forward indefinitely. The use of tax losses generated by the Company against other income may not provide a material benefit to Investors who do not have other taxable income from passive activities.

Limitation on Capital Losses

An Investor who is an individual may deduct only $3,000 of net capital losses every year (that is, capital losses that exceed capital gains). Net capital losses in excess of $3,000 per year may generally be carried forward indefinitely.

Limitation on Investment Interest

Interest that is characterized as “investment interest” generally may be deducted only against investment income. Investment interests would include, for example, interest paid by an Investor on a loan that was incurred to purchase Class A Investor Shares and interest paid by the Company to finance investments, while investment income would include dividends and interest but would not generally include long term capital gain. Thus, it is possible that an Investor would not be entitled to deduct all of his or her investment interest. Any investment interest that could not be deducted may generally be carried forward indefinitely.

Allocations of Profits and Losses

The profits and losses of the Company will be allocated among all of the owners of the Company (including the Investors) pursuant to the rules set forth in the LLC Agreement. In general, the Company will seek to allocate such profits and losses in a manner that corresponds with the distributions each owner is entitled to receive, i.e., so that tax allocations follow cash distributions. Such allocations will be respected by the IRS if they have “substantial economic effect” within the meaning of Code section 704(b). If they do not, the IRS could re-allocate items of income and loss among the owners.

Sale or Exchange of Class A Investor Shares

In general, the sale of Class A Investor Shares by an Investor will be treated as a sale of a capital asset. The amount of gain from such a sale will generally be equal to the difference between the selling price and the Investor’s tax basis. Such gain will generally be eligible for favorable long-term capital gain treatment if the Class A Investor Shares were held for at least 12 months. However, to the extent any of the sale proceeds are attributable to substantially appreciated inventory items or unrealized receivables, as defined in Code section 751, the Investor will recognize ordinary income.

A gift of Class A Investor Shares will be taxable if the donor-owner’s share of the Company’s debt is greater than his or her adjusted basis in the gifted interest. The gift could also give rise to federal gift tax liability. If the gift is made as a charitable contribution, the donor-owner is likely to realize gain greater than would be realized with respect to a non-charitable gift, since in general the owner will not be able to offset the entire amount of his adjusted basis in the donated Class A Investor Shares against the amount considered to be realized as a result of the gift (i.e., the debt of the Company).

Transfer of Class A Investor Shares by reason of death would not in general be a taxable event, although it is possible that the IRS would treat such a transfer as taxable where the decedent-owner’s share of debt exceeds the pre-death basis of his interest. The decedent-owner’s transferee will take a basis in the Class A Investor Shares equal to its fair market value at death (or, in certain circumstances, on the date six (6) months after death), increased by the transferee’s share of debt. For this purpose, the fair market value will not include the decedent’s share of taxable income to the extent attributable to the pre-death portion of the taxable year.

Treatment of Distributions

Upon the receipt of any distribution of cash or other property, including a distribution in liquidation of the Company, an Investor generally will recognize income only to the extent that the amount of cash and marketable securities he, she, or it receives exceed the basis of his, her, or its Class A Investor Shares. Any such gain generally will be considered as gain from the sale of Class A Investor Shares.

Alternative Minimum Tax

The Code imposes an alternative minimum tax on individuals and corporations. Certain items of the Company’s income and loss may be required to be taken into account in determining the alternative minimum tax liability of Investors.

Taxable Year

The Company will report its income and losses using the calendar year. In general, each Investor will report his, her, or its share of the Company’s income and losses for the taxable year of such Investor that includes December 31^st, i.e., the calendar year for individuals and other owners using the calendar year.

Section 754 Election

The Company may, but is not required to, make an election under Code section 754 on the sale of Class A Investor Shares or the death of an Investor. The result of such an election is to increase or decrease the tax basis of the assets of the Company for purposes of allocations made to the buyer or beneficiary which would, in turn, affect depreciation deductions and gain or loss on sale, among other items.

Tax Returns and Information; Audits; Penalties; Interest

The Company will furnish each Investor with the information needed to be included in his federal income tax returns. Each Investor is personally responsible for preparing and filing all personal tax returns that may be required as a result of his purchase of Class A Investor Shares. The tax returns of the Company will be prepared by accountants selected by the Company.

If the tax returns of the Company are audited, it is possible that substantial legal and accounting fees will have to be paid to substantiate our position and such fees would reduce the cash otherwise distributable to Investors. Such an audit may also result in adjustments to our tax returns, which adjustments, in turn, would require an adjustment to each Investor’s personal tax returns. An audit of our tax returns may also result in an audit of non-Company items on each Investor’s personal tax returns, which in turn could result in adjustments to such items. The Company is not obligated to contest adjustments proposed by the IRS.

Each Investor must either report Company items on his tax return consistent with the treatment on the information return of the Company or file a statement with his tax return identifying and explaining the inconsistency. Otherwise the IRS may treat such inconsistency as a computational error and re-compute and assess the tax without the usual procedural protections applicable to federal income tax deficiency proceedings.

The Code imposes interest and a variety of potential penalties on underpayments of tax.

Other U.S. Tax Consequences

The foregoing discussion addresses only selected issues involving Federal income taxes and does not address the impact of other taxes on an investment in the Company, including federal estate, gift, or generation-skipping taxes, or State and local income or inheritance taxes. Prospective Investors should consult their own tax advisors with respect to such matters. 

MANAGEMENT DISCUSSION

Operating Results

The Company was organized under the Delaware Limited Liability Company Act on January 23, 2020. As of the date of this Offering Circular, we have not yet begun operations other than those associated with general start-up and organizational matters. As of the date of this Offering Circular, the Company has not acquired any Projects and has no revenues or cash flows.

The Company is obligated to reimburse the Manager for expenses the Manager incurs in connection with the Offering, before the Offering Circular is qualified by the SEC. We currently estimate that those expenses will be approximately $100,000.

We intend to use the proceeds of this Offering to build, acquire, and operate Projects.

Apart from our efforts to raise money from the sale of Class A Investor Shares in this Offering, we are not aware of any trends or any demands, commitments, events, or uncertainties that will result in or that are reasonably likely to result in the our liquidity increasing or decreasing in any material way.

Liquidity and Capital Resources

The Company has no immediately available sources of liquidity other than the proceeds of the Offering. At the same time, the Company currently has no capital commitments. The Company intends to make capital commitments only if it raises sufficient funds in the Offering.

Trends

The Company is not aware of any trends, uncertainties, demands, commitments, or events that are reasonably likely to have a material effect on our net sales or revenues, income from continuing operations, profitability, liquidity, or capital resources. We caution, however, that any of the items listed in “Risks of Investing,” including but not limited to the risks presented by the COVID-19 pandemic, could have a material adverse effect.

OUR MANAGEMENT TEAM

Names, Ages, Etc. *

Family Relationships

There are no family relationships among the Executive Officers and significant employees of the Company.

Ownership of Related Entities

Energea Global, the Manager of the Company, is owned by Mike Silvestrini and Chris Sattler.

Energea Brazil, our affiliated Development Company in Brazil, is owned by Energea Global.

Business Experience

Mike Silvestrini

Mike co-founded Greenskies Renewable Energy, LLC (“Greenskies”) with a $35,000 family loan in 2008 and sold the company for more than $165 million enterprise value in 2017. Mike was directly responsible for closing over $500 million of project finance, building and owning over 400 solar projects ranging from 200kW to 5MW, creating industry-leading operations asset management departments and expanding the company’s footprint across 23 states from California to South Carolina. Greenskies was ranked #1 by market share for commercial and industrial solar developers by Greentech Media, with customers including Wal-Mart, Sam’s Club, Amazon, AT&T, Target and several of the largest electric utilities in the United States. It was also named one of the Best Places to Work by the Hartford Courant in 2016.

Mike was named “40 Under 40” by the Hartford Business Journal in 2012, and again by Connecticut Magazine in 2016. In 2017, he was named Entrepreneur of the Year by Junior Achievement. He was a national merit scholar at Boston University and was a Peace Corps volunteer in Mali, West Africa. He also serves on the Board of Directors of Big Life Foundation, a wildlife conservation and security group based in Kenya.

Mike lives in Connecticut with his wife and two children.

Chris Sattler

Chris is an experienced energy executive with a track record of startup success. He has founded over 10 companies with the majority in the retail energy industry. Previous positions include Vice President at Clean Energy Collective, President of Plant.Smart Energy Solutions, and Co-Founder and COO at North American Power.

As COO of North American Power, Chris led the company into 35+ utility markets throughout the United States, with over 1,000,000 residential and small commercial customers. In 2017, the company was sold to Calpine, the largest independent power producer in North America, for $115 million. At the time of sale, North American Power had annual gross sales in excess of $850 million.

Chris studied at the University of Connecticut, School of Business, and received a Bachelor’s degree in Real Estate and Urban Economics. He is also a Harvard Business School Alumni through the Program for Leadership Development. He lives in Rio De Janeiro.

Antonio Peres

Antonio Pires is a senior executive with more than 30 years of experience in the Energy sector. During this period he directly managed the implantation of more than 2GW of power projects, ranging from thermoelectric, cogeneration and hydropower.

In addition to his experience implementing large energy projects, he participated in the startup of Igarapava hydroelectric Consortium, being the first consortium of power generation in the country, and of which he was a member of the administrative council. He was also involved in the privatization process of Companhia Vale do Rio Doce, Companhia Estadual de Gas do Rio de Janeiro.

Throughout his professional life Antonio has worked with large national and multinational companies including CSN, El Paso Brasil, Thyssen Krop CSA and SNC Lavalin. In the case of El Paso and CSA, he was involved from the start of operations.

Antonio is a professional who always seeks new skills and is and ready for a challenge. He has a degree in mechanical engineering with a master's degree in Energy Planning, and an MBA in Business Management and Project Management, as well as LLM in Business Law.

Gray Reinhard

Gray is an experienced software engineer specializing in business intelligence tools across multiple industries. Early in Gray’s career, he worked primarily in E-Commerce where he built and supported sites for over 20 brands including several fortune 500 companies. From there, Gray moved into renewable energy where he developed the project management software for the country’s largest commercial solar installer. This custom platform managed everything from sales and financing to the construction, maintenance, and performance monitoring of over 400 solar projects.

Most recently, Gray served as CTO for real estate technology company Dwell Optimal which leverages technology to reinvent the corporate travel experience. Gray studied at Princeton University and currently splits his time between Greenpoint, Brooklyn and his cabin in the Catskills.

Legal Proceedings

Within the last five years, no Director, Executive Officer, or Significant Employee of the Company has been convicted of, or pleaded guilty or no contest to, any criminal matter, excluding traffic violations and other minor offenses.

Within the last five years, no Director, Executive Officer, or Significant Employee of the Company, no partnership of which an Executive Officer or Significant Employee was a general partner, and no corporation or other business association of which an Executive Officer or Significant Employee was an executive officer, has been a debtor in bankruptcy or any similar proceedings.

Summary of Business Experience

The following chart summarizes the business experienced of our management team over the last five years:

COMPENSATION OF MANAGEMENT

Overview

The people who run the Company make money from the Company in (only) three ways:

All three forms of compensation are discussed below.

The Company itself does not have any employees or payroll. For example, Mike Silvestrini, the Chief Executive Officer of the Manager, does not receive any salary, bonuses, or other compensation directly from the Company. Instead, all of his compensation is paid from the fees paid to the Manager and from the Promoted Interest. The same is true for all of the other executive officers and employees.

Fees

Co-Investment

The Manager (and possibly its affiliates) might purchase Class A Investor Shares. If so, they will be entitled to the same distributions as other Investors.

Promoted Interest

As described in “Securities Being Offered – Distributions” on page 28, the Manager is entitled to receive certain distributions from the Company that we refer to as the Manager’s “Promoted Interest.” How much money the Manager ultimately receives as a Promoted Interest depends on several factors, including:

Report to Investors

No less than once per year, the Company will provide Investors with a detailed statement showing:

In each case, the detailed statement will describe the services performed and the amount of compensation paid.

Method of Accounting

The compensation described in this section was calculated using the accrual method of accounting.

Stages of Development

The stages of the Company’s organization, development, and operation, and the compensation paid by the Company to the Manager and its affiliates during each stage, are as follows:

INTEREST OF MANAGEMENT AND OTHERS IN CERTAIN TRANSACTION

As of the date of this Offering Circular, we anticipate that the Company will enter into transactions with related parties in two circumstances:

The Company might enter into other transactions with related parties. If so, any compensation paid by the Company to the related party shall be (i) fair to the Company, and (ii) consistent with the transaction that would be paid to an unrelated party.

By “related party” we mean:

APPENDICES

Appendix 1-A

Energea Itaguaí I S.A.

Itaguaí, MG

30^th of April, 2020
NTP Draft

1.0 MW (AC) Solar

Developed by Energea Geração Distribuída De Energia Do Brasil Ltda

Project Summary

The project is a solar plant constructed in the state of Rio de Janeiro. The plant has been rented by Casas Pedro, a premier grocery chain operating in 40 locations that was founded in 1932. The 15-year rental contract will allow Casas Pedro to benefit from a substantial reduction in energy costs. Prosys Engenharia has been engaged as an EPC partner.

Project Details

System Details

Contract Details

Financial Details

Disclaimer

All major Energea contracts contain language ensuring that the following standards are upheld by all our partners.

Anti-Corruption

All operators and contractors must follow the rules for prevention of corruption as outlined in Brazilian law, particularly Law No. 8,429/1992 and Law No. 12,846/2013.

Any person or entity doing business with Energea agrees not to give or offer anything of value for the sake of gaining undue benefits. All people and parties will refrain from any and all fraudulent activity and use all efforts to ensure compliance.

Environmental

All operators and contractors are required to follow best industry practices both in Brazil and internationally with diligent and prudent adherence to common standards of environmental preservation.

Human Rights

All national and international human rights laws will be followed with mandatory monitoring to ensure compliance.

Permits & Interconnection

Permits

The project has received an environmental permit required to perform the installation of the project (“LI”).

Interconnection

The achieved Notice to Proceed status on the __st of ___, 2020 and to be operational by the ____ of ___, 20__. It has received its Parecer de Acesso, or permission to interconnect, from CEMIG, the interconnecting utility.

Site Control

Site Summary

The project is sited on a parcel of land rented from Mitra Diocesana de Itaguaí, the catholic diocese. The site is very secure and situated in a rural area. The diocese employees a caretaker who lives onsite and monitors the land 24/7.

The land is perfectly flat with no clearing required and quality soil for trenching and post driving with little resistance which should eliminate exposure to unforeseen construction costs.

The location benefits from very high irradiance with occasional cloud cover due to its proximity to the mountains.

Lease Agreement

Parties

Energea Itaguaí I S.A.

Mitra Diocesana De Itaguaí

Term

The lease term is for 15 years and Energea has the right to renew the agreement for an additional 15 years by notifying Mitra Diocesana De Itaguaí at least twelve months prior to the end of the initial term.

Price

The project will make a monthly payment of R$4,333 which is the pro-rata portion of the R$13,000 monthly rent charged for the plot that will accommodate three solar plants.

Penalties

Delayed payments are subject to a 2% fine and 1% interest per month delayed.

Property Taxes

The project is responsible for paying all property taxes as assessed for the site.

Termination Penalties

Design

Design Summary

The Itaguaí I solar project is located on a perfectly flat site allowing for a tracker based system which will greatly increase the expected captured irradiance.

The land is wide open with zero shading from trees or structures nearby. As such, the entire face of the array will be operational throughout the day.

The site is located very near the interconnection point with the utility resulting in little expected connection cost to the grid and high certainty that service will not be interrupted.

The project will employ 3,360 total JA Solar modules arranged in 120 parallel strings of 28 modules each. 8 Sungrow inverters will be used for power conversion.

JA and Sungrow are highly regarded manufacturers. The industry standard PVSyst software was used to optimize equipment selection and ensure peak production with minimal losses.

The expected useful life of the project and equipment is 25 years.

Key Assumptions

Loss Factors

Customer

Customer Summary

Casas Pedro (Nova Geração Comestíves Ltda) is a premium grocery retailer operating throughout the state of Rio de Janeiro. The company was founded in 1932 and is run by Felipe Mussalem, the third generation of family leadership.

In 2005, the company began expanding from its current footprint of six stores. At the close of 2019, the company had expanded to 40 locations and more than 1,000 employees.

Energea has independently reviewed and assessed the company’s private financial statements and has strong confidence in the company’s creditworthiness.

As Casas Pedro is a privately held company, its proprietary financial statements cannot be made available here out of respect for the company’s privacy. For any further due diligence questions, investors are encouraged to contact the team at Energea directly.

Rental Contract Summary

Parties

Nova Geração Comestíveis LTDA. (“Lessee”)

Gera Energia Brasil S.A. (“Lessor”)¹

Purpose

The Lessee is renting this solar power plant (Itaguaí I) to provide renewable energy to its members in the form of energy credits.

Term

The initial term for the project is for a period of 15 years beginning in the first month the Lessee receives energy credits from energy production of the power plant.

The term may be extended by written agreement from both parties at least sixty days before the end of the Initial Term.

Payments

The Lessee will pay the Lessor R$70,000 per month. The price will be adjusted annually to account for inflation in accordance with the Extended National Consumer Price Index (IPCA).

Delayed payments are subject to a 2% fine and 1% interest per month delayed.

Termination

Energea may terminate the contract without penalty if unable to find a suitable subcontractor, secure financing, or obtain any required authorizations or licenses needed to operate the power plant.

Early Termination Penalty

In the event of unilateral termination by either party, the party responsible for termination will pay the other party, within twenty days, the fine according to the following schedule:

Operations & Maintenance Contract Summary

Parties

Nova Geração Comestíveis LTDA. (“Lessee”)

Gera Energia Brasil S.A. (“Lessor”)¹

Purpose

This agreement ensures adequate power will be generated by the plant to provide for consumption by the customer. Compensation will be provided to the generator if the plant overperforms and remuneration to the customer if production falls below a guaranteed level.

Term

The initial term for the project is for a period of 15 years. The term may be extended by written agreement from both parties at least thirty days before the end of the initial term.

Price

The total effective price is R$0.570 per kWh of electricity.

[[TUSD and TE B3 rate] * the total production] – the rental amount paid – the green A4 TUSD rate (in R$/kW)

If the total hours generated multiplied by this effective rate exceeds the sum of the monthly rent and demand charge, the customer will pay the difference. If the lease and demand charge exceed the generation multiplied by the rate, the customer will instead receive a credit toward future payments.

Guarantees

In the event of unilateral termination, the terminating party will pay a fine of 50% of the remaining value of the contract to the other party.

Engineering, Procurement, and Construction

EPC Summary

Energea has designed a proprietary EPC contract to be used for all projects ensuring that construction progress and payments are properly aligned and requiring contractors to meet schedule and cost expectations or risk losing profit.

The contract establishes payment terms that make sense based on Energea’s extensive experience with the realities of project management.

The contract provides industry-leading control over the agreement’s costs, schedule, and terms.

EPC Contract

Parties

Energea Itaguaí I S.A.

Prosys Engenharia

Purpose

The Contractor will construct a solar power plant with a name- plate capacity of 6.505 MW DC connected to the grid in the state of Minas Gerais.

Price

Energea will pay a fixed price of R$3,437,901.99 disbursed according to the agreed upon EPC Milestones & Payments schedule.

Payments

Payments will only be considered due upon submission of a progress report and invoice from the Contractor to Energea. Payments are subject to a 5% retention to be released upon final acceptance of the project’s completion by Energea.

Effectiveness and Term

The agreement shall begin on the execution date and remain in effect until all the Contractor’s obligations are completed.

The Contractor will only begin work upon receipt of a Notice to Proceed from Energea.

Supervision

Energea may inspect the work of the Contractor at any time. The Contractor is responsible for providing evidence to show compliance with this agreement.

Warranties

The Contractor will warranty its services and those of its sub-contractors for 48 months beginning at Provisional Acceptance of the project by Energea.

The length of the warranty will either be as determined by the manufacturer or ten years for inverters, 20 years for trackers, and 25 years for modules, whichever is longer.

Insurance

For the duration of the agreement, the Contractor will have valid Insurance for Builder’s All Risks, Labor Liability, Comprehensive General Liability (in the amount of R$5,000,000), Automobile Liability (in the amount of R$300,000),

Transportation Insurance, Environmental Liability Insurance (in the amount of R$1,000,000), as well as any other insurance required by law.

Termination

The agreement may be terminated by written agreement between the parties, by Energea if the Contractor fails to comply with the terms or modifies its corporate structure, or by the Contractor if Energea fails to pay an undisputed invoice.

Penalties

For any breach of this agreement, the Contractor will pay Energea a penalty of R$5,000 per day for the duration of the breach. If the breach cannot be remedied, the total penalty will be R$20,000 per breach.

If any person working at the project is caused to suffer permanent harm due to the Contractor’s actions, the Contractor will pay Energea a penalty of 15% of the total contract price.

In the event of delay, the Contractor will pay a penalty equal to point one percent of the total contract price per day delayed. If the delay affects Energea’s ability to certify mechanical completion or provisional acceptance, the penalty will be one percent of the total contract price per day delayed.

If the project does not achieve or maintain the performance guaranteed in the agreement, the Contractor will pay a penalty equal to the price of the MWh deficit as purchased by Energea on the energy spot market.

EPC Schedule

EPC Milestones & Payments

Asset Management

Operations & Maintenance Agreement

Parties

Energea Itaguaí I S.A.

BEI – Brasil Energia Inteligente LTDA.